Welcome to Shree Soudha Architects. These Terms & Conditions govern the use of our website, services, and any agreements related to our architectural, interior design, and construction solutions. By engaging our services or accessing our website, you agree to the terms mentioned below.
Shree Soudha Architects provides architectural design, interior design, project management, construction, and consultancy services.
All project timelines, deliverables, and scope will be clearly mentioned in the official proposal/contract before work begins.
Any changes to project scope after commencement may result in revised timelines and additional charges.
Payment schedules will be mentioned in the agreement.
All fees must be paid as per the agreed milestones.
Delayed payments may result in suspension of work or additional late fees.
All designs, drawings, and concepts created by Shree Soudha Architects remain our intellectual property unless otherwise stated in the contract.
Clients are not permitted to reproduce, share, or modify our designs without written permission.
Clients must provide accurate information, approvals, and feedback in a timely manner to avoid project delays.
Any delay in approvals or decisions from the client may extend the project completion date.
All projects will follow applicable building codes, regulations, and government approvals.
Clients are responsible for providing necessary documents and approvals unless otherwise stated in the agreement.
Shree Soudha Architects will not be held liable for delays or damages caused by unforeseen circumstances, third-party vendors, or factors beyond our control.
We reserve the right to update or modify these Terms & Conditions at any time. Any changes will be reflected on this page with an updated effective date.
For any questions regarding these Terms & Conditions, please contact us:
📞 +91 96033 11169 / +91 86390 12237
📧 shreesoudhaarch@gmail.com
🏢 D.no.2-336/2,rd no.12, Adarshnagar, Chidiga, Kakinada, A.P.
Shree Soudha Architects specializes in architecture, interiors, exteriors, construction, and consultation services. With 18+ years of experience, we create innovative, high-quality spaces that reflect your vision